Terms & Conditions

Last Updated: September 6, 2026

Welcome to Digiatom Solutions Pvt. Ltd. (“Digiatom Solutions,” “Company,” “we,” “us,” or “our”). These Terms and Conditions (“Terms”) govern your access to and use of the website https://digiatomsolution.com (the “Website”) and any services, products, or content we provide.

By accessing our Website or engaging our services, you (“you,” “your,” “Client,” or “user”) agree to be bound by these Terms. If you do not agree with any part of these Terms, please do not use our Website or services.

1. Definitions

“Services” means the digital marketing, website development, mobile app development, branding and creative, artificial intelligence, automation, and any related consulting or technical services offered by Digiatom Solutions.
“Deliverables” means any work product, designs, code, content, reports, or materials created by us for you under a project or engagement.
“Agreement” means these Terms together with any proposal, quotation, statement of work, or written contract signed between you and us.

2. Acceptance of Terms

By using the Website or engaging our Services, you confirm that you are at least 18 years of age (or the age of majority in your jurisdiction) and that you have the legal authority to enter into a binding agreement.

If you are accepting these Terms on behalf of a company or other legal entity, you represent that you have the authority to bind that entity.

3. Our Services

Digiatom Solutions provides the following services, among others:

Digital marketing (SEO, social media marketing, performance/paid campaigns)
Website development (including WordPress and Shopify)
Mobile app development (Android and iOS)
Branding and creative services
Artificial intelligence, automation, and workflow optimisation

The specific scope, deliverables, timelines, and fees for any engagement will be set out in a separate proposal, quotation, or statement of work agreed between you and us.

In the event of a conflict between these Terms and a signed project agreement, the terms of the signed project agreement shall prevail for that engagement.

4. Quotations, Fees & Payment

All quotations are valid for [e.g., 30] days from the date issued unless otherwise stated.
Fees, payment schedules, and milestones will be specified in the applicable proposal or invoice.
Unless otherwise agreed in writing, an advance/deposit of [e.g., 50%] may be required before work begins, with the balance due [e.g., on delivery / as per agreed milestones].
Invoices are payable within [e.g., 7] days of the invoice date. Late payments may attract interest at [e.g., X% per month] and/or suspension of work until outstanding amounts are cleared.
All fees are exclusive of applicable taxes (including GST), which will be charged additionally where applicable.
Third-party costs, such as hosting, domains, premium plugins, themes, paid ad spend, licenses, or stock assets, are billed separately and are the Client’s responsibility unless expressly included in the quotation.

5. Client Responsibilities

To enable us to deliver the Services, you agree to:

Provide accurate, complete, and timely information, content, access, and materials as reasonably requested.
Provide feedback and approvals within agreed timeframes; delays on your side may affect project timelines.
Ensure you own or have the necessary rights and licenses to any content, logos, images, or materials you provide to us.
Comply with all applicable laws in connection with your use of our Services and Deliverables.

6. Project Timelines & Revisions

Estimated timelines are provided in good faith but are not guaranteed and may be affected by the scope of work, Client responsiveness, and factors outside our control.
The number of revision rounds included will be specified in the applicable proposal. Additional revisions or changes to the agreed scope (“scope creep”) may be subject to additional charges.

7. Intellectual Property

Our IP: All content on this Website—including text, graphics, logos, layouts, designs, and code—is owned by or licensed to Digiatom Solutions and is protected by applicable intellectual property laws. You may not copy, reproduce, or reuse it without our prior written consent.
Deliverables: Upon full payment of all applicable fees, ownership of the final Deliverables created specifically for you will transfer to you, except for:
(a) any pre-existing materials, tools, frameworks, or code libraries owned by us; and
(b) any third-party materials, which remain subject to their respective licenses.
Our Tools & Know-How: We retain ownership of all methodologies, techniques, frameworks, and reusable components developed by us.
Portfolio Rights: Unless you request otherwise in writing, we reserve the right to display and describe the work we have done for you in our portfolio, case studies, and marketing materials.

8. Third-Party Services & Links

Our Services and Website may integrate with or link to third-party platforms and tools, for example, hosting providers, payment gateways, analytics, advertising platforms, Calendly, and social media.

We are not responsible for the content, policies, availability, or practices of any third party, and your use of such services is governed by their own terms.

9. Acceptable Use of the Website

You agree not to:

Use the Website for any unlawful, harmful, or fraudulent purpose.
Attempt to gain unauthorised access to our systems, disrupt the Website, or introduce malware or malicious code.
Copy, scrape, or harvest data or content from the Website without permission.
Impersonate any person or entity or misrepresent your affiliation.

10. Confidentiality

Both parties agree to keep confidential any non-public business, technical, or commercial information disclosed during an engagement and to use it only for the purpose of performing under the Agreement.

This obligation survives the termination of the engagement.

11. Warranties & Disclaimers

We will perform the Services with reasonable skill and care and in a professional manner.
Except as expressly stated, the Website and Services are provided on an “as is” and “as available” basis without warranties of any kind, whether express or implied, including implied warranties of merchantability, fitness for a particular purpose, or non-infringement.
We do not warrant that the Website will be uninterrupted, error-free, or free of viruses, or that any specific marketing, ranking, traffic, or revenue result will be achieved. Digital marketing and SEO outcomes depend on many factors outside our control, including search engine and platform algorithms.

12. Limitation of Liability

To the maximum extent permitted by applicable law:

We shall not be liable for any indirect, incidental, special, consequential, or punitive damages, or for any loss of profits, revenue, data, or goodwill.
Our total aggregate liability arising out of or in connection with the Services or these Terms shall not exceed the total amount actually paid by you to us for the specific Services giving rise to the claim during the [e.g., three (3) months] preceding the event.
Nothing in these Terms excludes or limits liability that cannot be excluded or limited under applicable law.

13. Indemnification

You agree to indemnify and hold harmless Digiatom Solutions, its directors, employees, and contractors from any claims, damages, losses, or expenses (including reasonable legal fees) arising out of:

(a) your breach of these Terms;
(b) your misuse of the Website or Services; or
(c) any content or materials you provide to us that infringe the rights of a third party.

14. Cancellation & Termination

Either party may terminate an engagement by giving written notice as specified in the applicable project agreement.
On termination, you agree to pay for all Services performed and costs incurred up to the date of termination.
Any advance/deposit paid is [e.g., non-refundable / refundable subject to work completed] — please refer to the applicable project agreement.
We may suspend or terminate your access to the Website or Services immediately if you breach these Terms.

15. Force Majeure

We shall not be liable for any delay or failure to perform resulting from causes beyond our reasonable control, including natural disasters, acts of government, internet or power outages, third-party platform failures, or labour disputes.

16. Governing Law & Jurisdiction

These Terms shall be governed by and construed in accordance with the laws of India.

Subject to any applicable arbitration clause in a signed agreement, the courts at Mohali (Sahibzada Ajit Singh Nagar), Punjab, India shall have exclusive jurisdiction over any disputes arising out of or relating to these Terms.

17. Changes to These Terms

We may update or modify these Terms from time to time. The updated version will be posted on this page with a revised “Last Updated” date.

Your continued use of the Website or Services after any changes constitutes your acceptance of the revised Terms.

18. Severability

If any provision of these Terms is found to be invalid or unenforceable, the remaining provisions shall continue in full force and effect.

19. Contact Us

If you have any questions about these Terms, please contact us:

Digiatom Solutions Pvt. Ltd.
C157, Phase 7, Industrial Area, Sector 73,
Sahibzada Ajit Singh Nagar (Mohali), Punjab 160055, India

Phone: +91 79866 45450
Email: info@digiatomsolution.com
Website: https://digiatomsolution.com